Category Bids

Sources Sought - The U.S. Army Corps of Engineers, Charleston District (SAC) is conducting market research to identify qualified and interested contractors capable of performing complex heavy-civil and coastal flood-risk-management construction under a Single-Award Task Order Contract (SATOC). This notice is issued solely for information and planning purposes. It does not constitute a Request for Proposal (RFP), Invitation for Bid (IFB), or a commitment by the Government to issue a solicitation or award a contract. Responses will be used to assess industry interest, capability, bonding capacity, preferred delivery methods, and small business subcontracting opportunities.No proposals or offers are requested or will be accepted under this Sources Sought.

No telephone calls will be accepted requesting a bid package or solicitation. There is no bid package or solicitation currently available. In order to protect the integrity of any future procurement that may arise from this announcement, information regarding the technical point of contact will not be given and no appointments for presentations will be made./// The U.S. Government intends to issue a solicitation for a Design-Build Boat Maintenance Facility in Buliluyan, Palawan, Philippines, anticipated in November or December 2026. A Pre-Proposal Site Visit (PPSV) is tentatively scheduled for December 2026./// Interested offerors are encouraged to review the attached Pre- Solicitation Notice and other attachments for project details, PPSV information, and Base Access Request (BAR) requirements. The BAR submission deadline is November 23, 2026, at 11:00 AM Thailand Time.

This is a PRESOLICITATION NOTICE for the upcoming Solicitation 75H70127R00001 Fort Yates Pharmacy USP Renovation project in Fort Yates, ND (Sioux County), a construction project prepared in accordance with FAR Part 36. These construction services are in support of the Indian Health Service (IHS). The Government anticipates releasing the solicitation on or about mid or late November, 2026, and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://sam.gov under Contract Opportunities. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://sam.gov. SCOPE OF WORK: The purpose of this contract is to renovate the inpatient and outpatient pharmacies at Fort Yates Hospital in Fort Yates, North Dakota, to meet USP 795, 797, and 800 compounding standards in accordance with the construction drawings and specifications. Work includes phased renovations, temporary pharmacy setup, equipment relocation, conversion of existing spaces for pharmacy and storage uses, replacement of the outpatient pharmacy air handler, security installations, and a facility-wide building automation interface upgrade. The contractor shall maintain pharmacy operations, coordinate shutdowns, and meet applicable safety, infection control, permitting, tribal, and waste disposal requirements. Performance shall be completed within 270 days of the Notice to Proceed, with construction beginning only after completion of the McLaughlin pharmacy project. LOCATION OF PROJECT: All work shall be performed at the following: Fort Yates Hospital in Fort Yates, ND PERIOD OF PERFORMANCE: Period of Performance is 270 calendar days from date of notice to proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000 SITE VISIT: Details regarding the Site Visit will be included in the solicitation. CONTRACT TYPE: IHS intends to award a single Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable (LPTA) evaluation criteria. This project will be solicited as 100% set aside for Indian Small Business Economic Enterprise (ISBEE) pursuant to the Buy Indian Act under North American Industry Classification System (NAICS) code 236220, Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM. It is the responsibility of the contractor to check https://www.sam.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available � all documents for proposal purposes will be posted at the website for download by interested parties. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the initial notice including any subsequent amendments. No additional information is available other than what is noted herein. Firms are instructed not to call requesting more information.

Stated in the notice: CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000 SITE VISIT: Details regarding the Site Visit will be included in the solicitation.

Under an Interagency Agreement, the U.S. Department of Transportation John A. Volpe National Transportation Systems Center (Volpe Center) is providing support to the Federal Aviation Administration (FAA) Facilities Environmental Cleanup (ECU) Program. As part of this effort, a Remedial Action (RA) will be conducted at one facility in the FAA Eastern Service Area (ESA) to remove identified soil contamination. The site requiring remediation for lead- and polychlorinated biphenyl (PCB)-contaminated soils is QPI RCAG � Matawan, NJ (40.370895�,-74.220954�). The FAA�s ECU Program has identified the potential for environmental and human health risks and/or liability associated with the facility above based on prior research, known historic operations and practices, and required cleanup actions. The Contractor shall conduct all work in accordance with Federal, State, and local requirements. Where inconsistencies exist, the Contractor shall follow the most stringent requirement. The Contractor shall submit a draft Remediation and Restoration work plan (Work Plan) (where applicable) within ten (10) business days of the project kick-off meeting that addresses the project requirements below. This task involves the preparation and submission of a draft and final Work Plan. The Work Plan shall detail the technical approach and schedule for conducting all contaminated soil remediation, disposal, and site restoration activities described below. To assist with preparation of the Work Plan, the contractor shall thoroughly review the Government-furnished information (GFI) for pertinent information. The removal quantities and depths in the Preliminary Assessment/Site Investigation and Remedial Investigation reports (if provided) are to be used as a guide along with the estimated total quantities listed in this SOW Section 2.2.2. The Work Plan shall describe methods and procedures for performing soil remediation, disposal, and restoration. Disposal methods must be detailed by the contractor for the site. FAA has consulted a Licensed Site Remediation Professional (LSRP), and the LSRP will select and approve all disposal facilities where waste and debris is to be shipped. Disposal sampling and paperwork is the responsibility of the contractor. Confirmatory sampling has already been conducted at the site. Additionally, the work plan shall also identify any required permits needed to perform the work. Futhermore, components required with the Work Plan are the Site Safety and Health Plan (SSHP), which shall include personnel health and safety precautions to be followed. The work plan shall also include a brief Risk Management Plan that identifies major risks and hazards on each site and discusses ways to minimize these risks. An outline summarizing the required content of the work plan is Technical Approach (Method and procedures for soil remediation, removal, disposal a. Identification of required work permits and b. Site Safety Health Plan (SSHP). Risk Management Plan a. Identification of major risks and b.Risk mitigation plan. The contractor should expect a 5-business day Volpe Center review period between submission of the Draft Work Plan and receipt of Volpe Center comments. The Volpe Center and the Contractor shall meet to discuss any comments and changes, if necessary. The contractor shall make the changes and submit a Final Work Plan within 5 business days of the receipt of comments. Contaminated Soil Remediation: Preliminary Assessment/Site Investigation (PA/SI) and Remedial Investigation (RI) activities completed between 2020 and 2025 found soils at the below site containing contamination above FAA�s action levels, which are based on U.S. Environmental Protection Agency (EPA) and/or New Jersey Residential Soil Remediation Standards. Examples include lead-in-soil concentrations above 200 mg/kg (ppm) or PCB-in-soil concentrations above 0.25 mg/kg. See SOW for greater details.

Under an Interagency Agreement, the U.S. Department of Transportation John A. Volpe National Transportation Systems Center (Volpe Center) is providing support to the Federal Aviation Administration (FAA) Facilities Environmental Cleanup (ECU) Program. As part of this effort, a Remedial Action (RA) will be conducted at one facility in the FAA Eastern Service Area (ESA) to remove identified soil contamination. The site requiring remediation for lead- and polychlorinated biphenyl (PCB)-contaminated soils is QPI RCAG � Matawan, NJ (40.370895�,-74.220954�). The FAA�s ECU Program has identified the potential for environmental and human health risks and/or liability associated with the facility above based on prior research, known historic operations and practices, and required cleanup actions. The Contractor shall conduct all work in accordance with Federal, State, and local requirements. Where inconsistencies exist, the Contractor shall follow the most stringent requirement. The Contractor shall submit a draft Remediation and Restoration work plan (Work Plan) (where applicable) within ten (10) business days of the project kick-off meeting that addresses the project requirements below. This task involves the preparation and submission of a draft and final Work Plan. The Work Plan shall detail the technical approach and schedule for conducting all contaminated soil remediation, disposal, and site restoration activities described below. To assist with preparation of the Work Plan, the contractor shall thoroughly review the Government-furnished information (GFI) for pertinent information. The removal quantities and depths in the Preliminary Assessment/Site Investigation and Remedial Investigation reports (if provided) are to be used as a guide along with the estimated total quantities listed in this SOW Section 2.2.2. The Work Plan shall describe methods and procedures for performing soil remediation, disposal, and restoration. Disposal methods must be detailed by the contractor for the site. FAA has consulted a Licensed Site Remediation Professional (LSRP), and the LSRP will select and approve all disposal facilities where waste and debris is to be shipped. Disposal sampling and paperwork is the responsibility of the contractor. Confirmatory sampling has already been conducted at the site. Additionally, the work plan shall also identify any required permits needed to perform the work. Futhermore, components required with the Work Plan are the Site Safety and Health Plan (SSHP), which shall include personnel health and safety precautions to be followed. The work plan shall also include a brief Risk Management Plan that identifies major risks and hazards on each site and discusses ways to minimize these risks. An outline summarizing the required content of the work plan is Technical Approach (Method and procedures for soil remediation, removal, disposal a. Identification of required work permits and b. Site Safety Health Plan (SSHP). Risk Management Plan a. Identification of major risks and b.Risk mitigation plan. The contractor should expect a 5-business day Volpe Center review period between submission of the Draft Work Plan and receipt of Volpe Center comments. The Volpe Center and the Contractor shall meet to discuss any comments and changes, if necessary. The contractor shall make the changes and submit a Final Work Plan within 5 business days of the receipt of comments. Contaminated Soil Remediation: Preliminary Assessment/Site Investigation (PA/SI) and Remedial Investigation (RI) activities completed between 2020 and 2025 found soils at the below site containing contamination above FAA�s action levels, which are based on U.S. Environmental Protection Agency (EPA) and/or New Jersey Residential Soil Remediation Standards. Examples include lead-in-soil concentrations above 200 mg/kg (ppm) or PCB-in-soil concentrations above 0.25 mg/kg. See SOW for greater details.

U.S. Coast Guard Station Burlington requires removal and replacement of failed domestic hot-water heater equipment with new like-for-like equipment and restore reliable hot-water service to the galley, berthing spaces, and heads.see the attached statement of work. Site visits are urged and expected please contact the COR, contact information is in the statement of work. Qoutes must be submitted on company letterhead.

U.S. Coast Guard Station Burlington requires removal and replacement of failed domestic hot-water heater equipment with new like-for-like equipment and restore reliable hot-water service to the galley, berthing spaces, and heads.see the attached statement of work. Site visits are urged and expected please contact the COR, contact information is in the statement of work. Qoutes must be submitted on company letterhead.

U.S. Coast Guard Station Burlington requires removal and replacement of failed domestic hot-water heater equipment with new like-for-like equipment and restore reliable hot-water service to the galley, berthing spaces, and heads.see the attached statement of work. Site visits are urged and expected please contact the COR, contact information is in the statement of work. Qoutes must be submitted on company letterhead.

Notice to Industry The U.S. Army Corps of Engineers, Kansas City District is notifying industry that the following requirement is being pursued as a Progressive Design Build Other Transaction (PDB-OT) under 10 USC 2808a, Other Transaction for Construction. This notice is for informational purposes only to notify industry and seek feedback on the strategy. Project Overview Project Title: B95 Fire Station Addition Location: Ft. Leavenworth, KS Agency: USACE, Kansas City District (NWK) NAICS Code: 236220-Commerical and Industrial Building Construction The Kansas City District is seeking a Progressive Design Build partner to design and construct an addition to Building 95, a historic fire station. If you are interested in pursuing this PDB-OT, please send an email to the addresses below. We also ask that you provide responses to the following questions to better inform our decision and strategy. Discuss any thoughts (advantages and disadvantages/concerns) about participating in a collaborative PDB-OT procurement versus traditional FAR contracts. Discuss any experience utilizing progressive design build or construction manager at risk delivery methods. What qualifications do you believe should be most important for USACE NWK to prioritize during the down-select portion? Please respond by November 24, 2026, at 11:00 a.m. central standard time. Send your response to: Myleesa France at myleesa.s.france@usace.army.mil David Miller at david.f.miller@usace.army.mil Michael France at michael.g.france@usace.army.mil

This requirement is for the cleaning, inspection, and repair of the Mud Mountain Dam Sewage Lagoon. A site visit will be offered on 17 November 2026, see attachment for information and registration. Please pay attention to: Section L, Section M, and FAR 52.228-13 in the solicitation.

This is a pre-solicitation notice. This is NOT a solicitation. Do NOT submit proposals or questions in response to this notice. It is anticipated that the solicitation will be posted on Procurement Integrated Enterprise Environment (PIEE) website at https://piee.eb.mil/ by the end of November 2026. The solicitation is anticipated to be posted for 30 calendar days. The U.S. Army Corps of Engineers (USACE) Norfolk District (NAO) intends to issue an Invitation for Bid (IFB) acquisition for the NASA Wallops Shoreline Breakwaters Project in Accomack County, Virginia. This procurement will be conducted in accordance with FAR Part 14, Invitation for Bid (IFB). The Government intends to award a firm-fixed-price (FFP) contract. The requirement will be solicited as a 100% small business set aside. The applicable NAICS code is 237990, Other Heavy and Civil Engineering Construction (Dredging and Surface Cleanup Activities), with a small business standard of $45 million. In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the magnitude of construction is between $10,000,000 and $25,000,000. DESCRIPTION OF WORK The U.S. Army Corps of Engineers � Norfolk District is seeking eligible firms capable of constructing breakwaters along the beach of Wallops Island. The number of proposed breakwaters for this project will be between two to four and placed approximately 200 feet offshore (from Mean High Water elevation). Each breakwater will be constructed of Type II rip rap for armor stone and VDOT Class III stone for core stone. The weight of material for each breakwater is approximately 10,000 tons. Breakwaters are to be placed on 12-inch-thick marine mattress with geotextile fabric. Water depths for breakwater placement range between -9.5 ft and -12.0 ft NAVD88. Each breakwater will be constructed to a crest height of +7 ft NAVD88. Material for breakwaters may be transported to the project site either by land or sea. Construction of breakwaters may occur either by land or sea. Various work restrictions are expected due to active rocket launches within the vicinity of the project site, which will require all construction activities to stop and personnel to vacate the premises for hours to day(s). The construction completion date will be approximately 325 calendar days from the issuance of Notice to Proceed (NTP). Contractors will be required to submit bid bonds documents with the proposal. The successful awardee will be required to provide 100% payment and performance bonds for the project. The effort will be solicited and awarded utilizing the Sealed Bid procedures under FAR Part 14. Anticipated solicitation issuance time frame is on or about the end of November 2026. THIS PROJECT IS A 100% SMALL BUSINESS SET ASIDE PROCUREMENT INVITATION FOR SEALED BID. The Government intends to award a firm fixed price contract using INVITATION FOR BID WITH PRE-AWARD SURVEY and procedures outlined in FAR 36 and FAR 14. Pre-award survey will determine contractor responsibility in accordance with FAR 9.104. Bidders will be evaluated on both pre-award survey and conformance to the solicitation and price. The Government reserves the right to reject any or all Bids; and to award the contract to other than the lowest total price and to award to the bidder submitting the lowest bid determined by the Government to be responsible. Bid bonds will be required with bid submittals. In addition, the awardee must be found responsible in accordance with FAR 9.1. The below Pre-Award Survey Information will be requested of the apparent low offeror. This information is not required to be responsive to the Invitation for Bid. a) Current commitments and expected dates of completion. b) One (1) signed bank reference demonstrating adequate financial resources. If bidder�s firm has a line of credit � provide information on how many figures bidder can borrow against the line of credit (i.e. medium 6 figures � exact line of credit is not required). c) The bidder shall provide the latest three (3) complete fiscal year financial statements for the prime contractor, certified by an independent accounting firm, if practicable, or signed by an authorized officer of the organization. Submit evidence of availability of working/operating capital, which will be used for the performance of the resultant contract. For Joint Venture arrangements, submit the latest three complete fiscal year financial statements for each company in the Joint Venture and discuss the financial responsibilities among the companies. The Government may also utilize Dun & Bradstreet reports to evaluate the financial capacity of the bidder. Definitive Responsibility Crieteria: This requirement will use Definitive Responsibility Criteria (DRC) which are specific and objective standards established to inform the Contracting Officer. In accordance with FAR 9.104-2. These criteria will be used to assess whether the apparent low bidder can demonstrate the expertise and specialized facilities needed for adequate contract performance. The inability of a contractor otherwise eligible for award to demonstrate minimally acceptable experience as measured by the DRC may result in the Contracting Officer determining the contractor is not responsible. The Definitive Responsibility Criteria will assess the following work items: 1. The apparent low bidder shall provide one documented experience of underwaterplacing at least 5,000 square yards of geotextile fabric or marine mattresses within the last 7 years. 2. The apparent low bidder shall provide documented experience proving successfully built at least one marine stone structure of at least 15,000 tons within the last 7 years. This notice does not constitute an invitation for bid. The IFB and accompanying documents will be issued electronically and will be uploaded to the Procurement Integrated Enterprise Environment (PIEE) website at https://piee.eb.mil/ on or about the end of November 2026. Notification of any changes to this pre-solicitation will only be made on this website. Therefore, it is the offerors responsibility to check the website regularly for any posted changes to the pre-solicitation notice, release of the solicitation, specification, drawings, and all subsequent amendments. Telephone calls or written requests for the IFB package will NOT be accepted. Prospective bidders are responsible for monitoring at https://piee.eb.mil/ to respond to the solicitation and any amendments or other information regarding this acquisition. IT IS THE SOLE RESPONSIBILITY OF THE OFFEROR TO CONTINUALLY VIEW THE WEBSITE FOR CHANGES. No hard copies will be available. Prospective bidders are responsible for monitoring SAM.gov to respond to the solicitation and any amendments or other information regarding this acquisition. Prospective bidders are required to be registered in SAM when submitting an offer and shall continue to be registered until time of award, during performance, and through final payment of any contract. NOTE: Online Representations and Certifications Applications apply to this solicitation. Inquires must be directed to ProjNet in accordance with the forthcoming Solicitation document.

Stated in the notice: In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the magnitude of construction is between $10,000,000 and $25,000,000.

This is a pre-solicitation notice. This is NOT a solicitation. Do NOT submit proposals or questions in response to this notice. It is anticipated that the solicitation will be posted on Procurement Integrated Enterprise Environment (PIEE) website at https://piee.eb.mil/ by the end of November 2026. The solicitation is anticipated to be posted for 30 calendar days. The U.S. Army Corps of Engineers (USACE) Norfolk District (NAO) intends to issue an Invitation for Bid (IFB) acquisition for the NASA Wallops Shoreline Breakwaters Project in Accomack County, Virginia. This procurement will be conducted in accordance with FAR Part 14, Invitation for Bid (IFB). The Government intends to award a firm-fixed-price (FFP) contract. The requirement will be solicited as a 100% small business set aside. The applicable NAICS code is 237990, Other Heavy and Civil Engineering Construction (Dredging and Surface Cleanup Activities), with a small business standard of $45 million. In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the magnitude of construction is between $10,000,000 and $25,000,000. DESCRIPTION OF WORK The U.S. Army Corps of Engineers � Norfolk District is seeking eligible firms capable of constructing breakwaters along the beach of Wallops Island. The number of proposed breakwaters for this project will be between two to four and placed approximately 200 feet offshore (from Mean High Water elevation). Each breakwater will be constructed of Type II rip rap for armor stone and VDOT Class III stone for core stone. The weight of material for each breakwater is approximately 10,000 tons. Breakwaters are to be placed on 12-inch-thick marine mattress with geotextile fabric. Water depths for breakwater placement range between -9.5 ft and -12.0 ft NAVD88. Each breakwater will be constructed to a crest height of +7 ft NAVD88. Material for breakwaters may be transported to the project site either by land or sea. Construction of breakwaters may occur either by land or sea. Various work restrictions are expected due to active rocket launches within the vicinity of the project site, which will require all construction activities to stop and personnel to vacate the premises for hours to day(s). The construction completion date will be approximately 325 calendar days from the issuance of Notice to Proceed (NTP). Contractors will be required to submit bid bonds documents with the proposal. The successful awardee will be required to provide 100% payment and performance bonds for the project. The effort will be solicited and awarded utilizing the Sealed Bid procedures under FAR Part 14. Anticipated solicitation issuance time frame is on or about the end of November 2026. THIS PROJECT IS A 100% SMALL BUSINESS SET ASIDE PROCUREMENT INVITATION FOR SEALED BID. The Government intends to award a firm fixed price contract using INVITATION FOR BID WITH PRE-AWARD SURVEY and procedures outlined in FAR 36 and FAR 14. Pre-award survey will determine contractor responsibility in accordance with FAR 9.104. Bidders will be evaluated on both pre-award survey and conformance to the solicitation and price. The Government reserves the right to reject any or all Bids; and to award the contract to other than the lowest total price and to award to the bidder submitting the lowest bid determined by the Government to be responsible. Bid bonds will be required with bid submittals. In addition, the awardee must be found responsible in accordance with FAR 9.1. The below Pre-Award Survey Information will be requested of the apparent low offeror. This information is not required to be responsive to the Invitation for Bid. a) Current commitments and expected dates of completion. b) One (1) signed bank reference demonstrating adequate financial resources. If bidder�s firm has a line of credit � provide information on how many figures bidder can borrow against the line of credit (i.e. medium 6 figures � exact line of credit is not required). c) The bidder shall provide the latest three (3) complete fiscal year financial statements for the prime contractor, certified by an independent accounting firm, if practicable, or signed by an authorized officer of the organization. Submit evidence of availability of working/operating capital, which will be used for the performance of the resultant contract. For Joint Venture arrangements, submit the latest three complete fiscal year financial statements for each company in the Joint Venture and discuss the financial responsibilities among the companies. The Government may also utilize Dun & Bradstreet reports to evaluate the financial capacity of the bidder. Definitive Responsibility Crieteria: This requirement will use Definitive Responsibility Criteria (DRC) which are specific and objective standards established to inform the Contracting Officer. In accordance with FAR 9.104. These criteria will be used to assess whether the apparent low bidder can demonstrate the expertise and specialized facilities needed for adequate contract performance. The inability of a contractor otherwise eligible for award to demonstrate minimally acceptable experience as measured by the DRC may result in the Contracting Officer determining the contractor is not responsible. The Definitive Responsibility Criteria will assess the following work items: 1. The apparent low bidder shall provide one documented experience of underwaterplacing at least 5,000 square yards of geotextile fabric or marine mattresses within the last 7 years. 2. The apparent low bidder shall provide documented experience proving successfully built at least one marine stone structure of at least 15,000 tons within the last 7 years. This notice does not constitute an invitation for bid. The IFB and accompanying documents will be issued electronically and will be uploaded to the Procurement Integrated Enterprise Environment (PIEE) website at https://piee.eb.mil/ on or about the end of November 2026. Notification of any changes to this pre-solicitation will only be made on this website. Therefore, it is the offerors responsibility to check the website regularly for any posted changes to the pre-solicitation notice, release of the solicitation, specification, drawings, and all subsequent amendments. Telephone calls or written requests for the IFB package will NOT be accepted. Prospective bidders are responsible for monitoring at https://piee.eb.mil/ to respond to the solicitation and any amendments or other information regarding this acquisition. IT IS THE SOLE RESPONSIBILITY OF THE OFFEROR TO CONTINUALLY VIEW THE WEBSITE FOR CHANGES. No hard copies will be available. Prospective bidders are responsible for monitoring SAM.gov to respond to the solicitation and any amendments or other information regarding this acquisition. Prospective bidders are required to be registered in SAM when submitting an offer and shall continue to be registered until time of award, during performance, and through final payment of any contract. NOTE: Online Representations and Certifications Applications apply to this solicitation. Inquires must be directed to ProjNet in accordance with the forthcoming Solicitation document.

Stated in the notice: In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the magnitude of construction is between $10,000,000 and $25,000,000.

09-Nov-2026: Posting Amendment 0004. Offer due date extended to 24 Nov 2026, 3:30 PM HST. Updating water and electricity utility charge rates in solicitation. Incorporating Questions and Answers to the plans and specifications. Incorporating project KNMD209085 and KNMD209086, drawings and specifications Addendum A.____26-Oct-2026: Posting Amendment 0003, Questions and partial answers to the plans and specifications. Additional answers once received to questions related to the plans and specifications will be incorporated in a future amendment. ____21-Oct-2026: Posting Amendment 0002. Extending the offer due date to 12 Nov 2026, 10:00 AM HST. Incorporating new wage determination, questions and answers to the solicitation, and questions and partial answers to the plans and specifications. Additional answers once received to questions related to the plans and specifications will be incorporated in a future amendment. ____07-Oct-2026: Posting Amendment 0001, preproposal conference slides and sign-in attendance sheet in PIEE/Solicitation Module. The purpose of Amendment 0001 is to change Questions due NLT 16 Oct 2026, 5:00 PM HST, and the offer due date to 30 Oct 2026, 3:30 PM HST. ____23-Sep-2026: This is a Solicitation Notice, Request for Proposal. Single Project RFP Set-Aside for Small Businesses NAICS Code: 236220 - Commercial and Institutional Building Construction. The Hawaii National Guard intends to issue a Request for Proposals (RFP) to award a single firm fixed-price contract for services, non-personal, to provide all plant, labor, transportation, materials, tools, equipment, appliances and supervision necessary for the Construction of KNMD209085 Munitions Maintenance and Inspection Facility and KNMD209086 Conventional Munitions Cube Storage Addition located on the Hawaii Air National Guard campus, at Joint Base Pearl Harbor-Hickam (JBPHH), Hawaii. These projects will be concurrent. KNMD209085 Munitions Maintenance and Inspection Facility - Construct a new Munitions Maintenance and Inspections facility by utilizing conventional design and construction methods to accommodate the facility mission. This project has a statutory cost limitation $14M for Unspecified Minor Military Construction (UMMC) Project - Adjustment of Dollar Limitations for Location pursuant to 10 USC Section 2805. Project square footage is estimated at 2,400 SF. Work covered in this project includes but is not limited to: Micro-pile Foundations: Specialized foundation engineering featuring micro-piles to mitigate challenging soil conditions and ensure seismic structural integrity. Cast-in-Place Concrete: Constructing robust concrete slab-on-grade, concrete walls, capping beams, and associated structural masonry elements. Structural Framing and Enclosure: Utilizing cold-formed metal framing, insulated metal wall panels, and structural steel support systems. Roofing: Installation of high-performance standing seam metal roofing, complete with prefinished gutters, downspouts, and weather barrier wraps. Specialized Systems: Installation of mechanical HVAC systems (including specialized 20-ton air conditioning systems), interior plumbing, lightning/grounding protection, and communication infrastructure. Fire Protection: A complete fire alarm-mass notification system and wet-pipe sprinkler suppression system. In addition to the base work described above, the solicitation will include the following option line items: 1. MAC Pad - Construct 1,167 SY concrete pad for the Material Assembly Center (MAC), required for constructing munitions, along with new asphalt pavement for access and egress to the facility maintenance bays. KNMD209086 Conventional Munitions Cube Storage Addition - Construct an addition to the Munitions Cube Storage Facility (B3552) utilizing conventional design and construction methods to support the F-22 mission. This project has a statutory cost limitation $14M for Unspecified Minor Military Construction (UMMC) Project - Adjustment of Dollar Limitations for Location pursuant to 10 USC Section 2805. Project square footage is estimated at 1,320 SF. Work covered in this project includes but is not limited to: Substructure and Enclosure: Micro-pile foundations, concrete wall structures, cast-in-place concrete slabs, and 12 in. thick concrete walls designed for high-hazard storage specifications. Framing and Roofing: Structural steel framing, roof joists, and standing seam metal roofing matching existing facility standards. Exterior Elements: Erection of new asphalt pavement adjacent to the existing facility access to provide adequate logistics and material handling access around the new facility addition. Specialized Protection: Maintenance facility lightning and grounding protection systems, along with integrated fire detection and alarm reporting systems connected back to the base reporting system. APPLICABLE TO BOTH PROJECTS: RAB Lighting exterior wall packs and area lights are sole source/brand name specific for compatibility with existing installation systems (noted justifications will be included with solicitation). Project Phasing and Security Gates: The contractor will be required to erect a temporary security fence around the construction zone in accordance with the project staging and phasing drawings. Escort Requirements: Escort personnel shall be required when erecting the temporary security fence, performing work occurring outside the temporary security fence, and connecting utilities to the existing system. Secured Zone Access: Once the temporary security fencing is approved and accepted by the Contracting Officers Representative (COR), no escort shall be required within the active secured work zone during construction, allowing the contractor to work within the secured boundary unimpeded. The magnitude of construction is between $10,000,000 and $25,000,000 total. KNMD209085 Munitions Maintenance and Inspection Facility project duration will be 733 calendar days after notice to proceed to include inspection and punch list. KNMD209086 Conventional Munitions Cube Storage Addition project duration will be 456 calendar days after notice to proceed to include inspection and punch list. This action is being solicited as a set-aside 100% for Small Businesses. The North American Industry Classification System (NAICS) Code is 236220, with a small business size standard of $45,000,000. A pre-proposal conference is scheduled 01 October 2026, 08:00 am local time, location to be provided in the solicitation. Interested contractors are encouraged to attend and shall follow conference registration and base access requirements shown in the solicitation. A site visit will follow the preproposal conference. All questions for the pre-bid conference must be submitted by 28 September via email to cezar.y.deveas.mil@army.mil and copy to anthony.g.reyes1.civ@army.mil. The solicitation closing date is 28 October 2026. Actual dates and times will be identified in the solicitation. The source selection process will be conducted in accordance with the Source Selection Procedures described in FAR 15.2, DFARS 215.2, and AFARS 5115.2. Evaluation factors include Technical Capability, Past Performance and Price. The Government intends to award a contract without conducting discussions. Interested offerors must be registered in the System for Award Management (SAM). To register go to www.SAM.gov. Instructions for registering are on the web page (there is no fee for registration). The solicitation and associated information will be available only from the Contract Opportunities page at SAM.gov. The solicitation and associated information will be posted within Procurement Integrated Enterprise Environment (PIEE) Solicitation Module and subsequently uploaded into the Contract Opportunities page at SAM.gov. Per the solicitation requirements, Offerors are required to submit their proposals through the vendor portal for solicitations within the PIEE platform. A Proposal Manager role is required to submit an offer to a solicitation posted in the PIEE Solicitation Module. A PIEE Solicitation Module Vendor Access Instructions is attached. If your company is new to PIEE and has no Account Administrator, the link below provides the general steps in getting started as a vendor to use the PIEE Solicitation Module and other PIEE applications: https://pieetraining.eb.mil/wbt/xhtml/wbt/portal/overview/vendorRegister.xhtml. This solicitation is not an invitation for bids and there will not be a formal public bid opening. All inquiries must be in writing, preferably via email to the persons specified in the solicitation. All answers will be provided in writing via posting to SAM.gov. If you have any questions concerning this procurement you are encouraged to email your questions to cezar.y.deveas.mil@army.mil and copy to anthony.g.reyes1.civ@army.mil. Your attention is directed to FAR clause 52.219-14(e)(3) (DEVIATION 2021-O0008), LIMITATIONS ON SUBCONTRACTING, which states -By submission of an offer and execution of a contract, the Offeror/Contractor agrees in performance of the contract for General construction, it will not pay more than 85 percent of the amount paid by the Government for contract performance, excluding the cost of materials, to subcontractors that are not similarly situated entities. Any work that a similarly situated entity further subcontracts will count towards the prime contractors 85 percent subcontract amount that cannot be exceeded-. In accordance with RFO FAR 36.101-4, the following information is provided: (a) There are no agency-specific policies or procedures that apply to the definitization of equitable adjustments for change orders under construction contracts. (b) No data is available regarding the timely definitization of equitable adjustments for change orders under construction contracts. DISCLAIMER: The official plans and specifications are located on the official Government webpage and the Government is not liable for information furnished by any other source. Amendments, if/when issued will be posted to Contract Opportunities for electronic downloading. This will normally be the only method of distributing amendments prior to closing; therefore, it is the offerors responsibility to check the website periodically for any amendments to the solicitation. Websites are occasionally inaccessible for various reasons. The Government is not responsible for any loss of Internet connectivity or for an offerors inability to access the documents posted on the referenced web pages. The Government will not issue paper copies.

Stated in the notice: The magnitude of construction is between $10,000,000 and $25,000,000 total.

The Central Virginia VA Health Care System is requesting loading dock concrete repair at the Richmond VA Medical Center (VAMC). The loading dock treads and risers are damaged and is a safety concern. Period of Performance: project should take approximately 90 days to complete.

The purpose of this amendment (1) is to provide consolidated Government responses to questions received, resolve identified inconsistencies, and clarify solicitation requirements. Except as changed by this amendment, all other terms and conditions remain unchanged.

Only Civil/Paving MACC Contractors listed on the General Requirements cover page may submit a proposal for this ROICC Camp Lejeune area of responsibility project. See attached documents for scope of work and any applicable drawings.

NGWSP Turnout Buildings

DINO REPLACE SWING ARM GATES

Fort Peck JDC Fire Alarm System Upgrade

Amendment 00001: Amendment 00001 includes information on a site visit to be conducted on November 13, 2026 at 12:00 pm EST. The address for this site visit is: 1201 E 185th St, Cleveland, OH 44119. Additionally, this amendment includes changes to the plans and specs to no longer include tree felling as part of the project requirements. The contractor will still be required to remove the felled trees from the work site. Please acknowledge this amendment in the submission of your bids. This posting is an Invitation for Bid (IFB) issued by the U.S. Army Corps of Engineers, Buffalo District, for the construction of the Euclid Creek Fishway at the existing Euclid Creek Spillway in Cleveland, Cuyahoga County, Ohio. The project includes construction of a fishway within the existing spillway and modification of the spillway as necessary to accommodate the fishway. Additional work includes construction of an access road, retaining wall, railing, and road gate; tieback design and tieback fabrication/installation for the retaining wall; and site restoration in accordance with the plans and specifications. Associated work includes concrete removal, excavation, dewatering, clearing and grubbing, and other incidental work necessary to provide a complete and usable project. The North American Industry Classification System (NAICS) code for this procurement is 237990, Other Heavy and Civil Engineering Construction. This acquisition will be competed as a 100% Small Business Set-Aside. The magnitude of construction is estimated to be between $5,000,000 and $10,000,000.Please be advised that this requirement is subject to change and may be revised or canceled at any time prior to award.

Stated in the notice: The magnitude of construction is estimated to be between $5,000,000 and $10,000,000.Please be advised that this requirement is subject to change and may be revised or canceled at any time prior to award.

This is a combined synopsis/solicitation for commercial products and commercial services prepared in accordance with the format Revolutionary FAR Overhaul (RFO) in Federal Acquisition Regulation (FAR) subpart 12.202, �Streamlined Procedures for Evaluation and Solicitation for Commercial Products and Commercial Services,� as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested, and a written solicitation document will not be issued. This solicitation is issued as an RFQ. The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2025-06, effective 8/26/2025. This solicitation is set-aside for 100% total Service-Disabled Veteran-Owned Small Businesses (SDVOSBs). The associated North American Industrial Classification System (NAICS) code for this procurement is 238220 with a small business size standard of $19.0 Million. The FSC/PSC is J041. The award will be made to the quote most advantageous to the Government and best meets the requirement described in the Statement of Work (SOW). Price and Other Factors: See Attachment 2, FAR 52.212-2 �Evaluation� The Long Beach Veterans Affairs Healthcare System (LBVAHCS) is seeking Preventative Maintenance, Inspection, and Repair Services (PMI&R) for Government-Owned Fume Hood/Safety Cabinets. All Solicitation inquiries are due on November 16, 2026, and all proposal responses are due on November 23, 2026, by email to Contracting Officer Daniel Kneizeh, daniel.kneizeh@va.gov. Please reference the details below and the Solicitation attachments for further information.

The U.S. Army Corps of Engineers, New York District is issuing an invitation for bid to award a Firm Fixed Price construction contract for the demolition of existing building, site Improvements and provide a turnkey modular office facility. The scope includes the demolition of an existing 10,000 SF building (with basement, in-ground pool, and pool shed), Hazardous Materials Abatement and Disposal, Site Improvements (SWPPP Controls, Sidewalks, Parking, Landscaping, Temp Fencing, Utilities Infrastructure including Water, Sewer, Electrical, Telecom tie-ins), and construction of a new office space of approximately 5,700 square feet, composed of custom modular units. The facility will be a single-story complex with a u-shaped space opening onto a small deck. It will house open offices with cubicles, six private offices, two conference rooms, four single-user bathrooms, a kitchenette/pantry room, lactation room, storage closets, and a mechanical room. The project scope encompasses incidental demolition, site prep work, foundations, underground utility hook ups, and site lighting. The contractor will also be responsible for providing furniture, fixtures, and equipment based upon the drawings and specifications. The building and site infrastructure are required to have a minimum life expectancy of 10 to 15 years. The contract duration will be 136 calendar days for the entire project with phasing work involved. NAICS: 236220 Size standard: $45 million. Project magnitude is between $1,000,000 - $5,000,000. Site visit has been scheduled for-- Tuesday 17 November 2026, at 10AM EST. Persons attending the site visit should arrive at project site: 307 Steamboat Road building entrance on the US Merchant Marine Academy Campus Meeting location: 307 Steamboat Road Kings Point NY 11024. Time of meeting: 1000hr Duration: 1 hr (1000-1100) The POC for submission of information for campus access will be Mohenda.R.Surage@usace.army.mil and Julie.Kim@usace.army.mil Persons will be required to provide the following information by 2:00 pm on 16 November 2026. Project location is near the end of Steamboat Road toward the waterfront. Folks arriving lateto the visit WILL NOT be accommodated. Name DOB Company Valid Real ID will be required (a passport would be an acceptable alternative).

Stated in the notice: Project magnitude is between $1,000,000 - $5,000,000.

The U.S. Army Corps of Engineers, New York District is issuing an invitation for bid to award a Firm Fixed Price construction contract for the demolition of existing building, site Improvements and provide a turnkey modular office facility. The scope includes the demolition of an existing 10,000 SF building (with basement, in-ground pool, and pool shed), Hazardous Materials Abatement and Disposal, Site Improvements (SWPPP Controls, Sidewalks, Parking, Landscaping, Temp Fencing, Utilities Infrastructure including Water, Sewer, Electrical, Telecom tie-ins), and construction of a new office space of approximately 5,700 square feet, composed of custom modular units. The facility will be a single-story complex with a u-shaped space opening onto a small deck. It will house open offices with cubicles, six private offices, two conference rooms, four single-user bathrooms, a kitchenette/pantry room, lactation room, storage closets, and a mechanical room. The project scope encompasses incidental demolition, site prep work, foundations, underground utility hook ups, and site lighting. The contractor will also be responsible for providing furniture, fixtures, and equipment based upon the drawings and specifications. The building and site infrastructure are required to have a minimum life expectancy of 10 to 15 years. The contract duration will be 136 calendar days for the entire project with phasing work involved. NAICS: 236220 Size standard: $45 million. Project magnitude is between $1,000,000 - $5,000,000.

Stated in the notice: Project magnitude is between $1,000,000 - $5,000,000.

The U.S. Army Corps of Engineers, New York District is issuing an invitation for bid to award a Firm Fixed Price construction contract for the demolition of existing building, site Improvements and provide a turnkey modular office facility. The scope includes the demolition of an existing 10,000 SF building (with basement, in-ground pool, and pool shed), Hazardous Materials Abatement and Disposal, Site Improvements (SWPPP Controls, Sidewalks, Parking, Landscaping, Temp Fencing, Utilities Infrastructure including Water, Sewer, Electrical, Telecom tie-ins), and construction of a new office space of approximately 5,700 square feet, composed of custom modular units. The facility will be a single-story complex with a u-shaped space opening onto a small deck. It will house open offices with cubicles, six private offices, two conference rooms, four single-user bathrooms, a kitchenette/pantry room, lactation room, storage closets, and a mechanical room. The project scope encompasses incidental demolition, site prep work, foundations, underground utility hook ups, and site lighting. The contractor will also be responsible for providing furniture, fixtures, and equipment based upon the drawings and specifications. The building and site infrastructure are required to have a minimum life expectancy of 10 to 15 years. The contract duration will be 136 calendar days for the entire project with phasing work involved. NAICS: 236220 Size standard: $45 million. Project magnitude is between $1,000,000 - $5,000,000. Site visit has been scheduled for-- Tuesday 17 November 2026, at 10AM EST. Persons attending the site visit should arrive at project site: 307 Steamboat Road building entrance on the US Merchant Marine Academy Campus Meeting location: 307 Steamboat Road Kings Point NY 11024. Time of meeting: 1000hr Duration: 1 hr (1000-1100) The POC for submission of information for campus access will be Mohenda.R.Surage@usace.army.mil and Julie.Kim@usace.army.mil Persons will be required to provide the following information by 2:00 pm on 16 November 2026. Project location is near the end of Steamboat Road toward the waterfront. Folks arriving late to the visit WILL NOT be accommodated. Name DOB Company Valid Real ID will be required (a passport would be an acceptable alternative).

Stated in the notice: Project magnitude is between $1,000,000 - $5,000,000.